This Time and Materials Contract (hereinafter referred to as the "Contract") is entered into and shall be effective as of [Contract Effective Date] (hereinafter referred to as the "Effective Date"),
By and Between
[Sender Company] reinafter referred to as the “Company”), residing at [Sender Company Address] and;
[Contractor Name] (hereinafter referred to as the “Contractor”) has its principal office at [Contractor Address].
The Company and the Contractor are collectively referred to as the "Parties" and individually as the "Party."
WHEREAS the Company desires for the Contractor to provide Time and Materials for [Purpose of the Service];
WHEREAS the Contractor agrees to provide such Time and Materials to the Company for [Company Goal].
THEREFORE, in consideration of the mutual covenants and commitments contained herein, the Parties do hereby agree as follows:
TERMS AND CONDITIONS.
1. CONTRACTOR'S RESPONSIBILITY.
The Contractor hereby agrees to provide the Time and Materials defined in this Contract:
The Contractor agrees to provide the necessary time and materials as defined in this Contract. The scope of work includes [Scope of Work], requiring approximately [No. of Labor Hours] hour(s) of labor. The Contractor will also supply the following materials:
[Materials List]
2. WORK COMPLETION SCHEDULE.
The Contractor shall plan and execute the work in accordance with a detailed schedule mutually agreed upon by the Parties.
The schedule will include:
(a) Start Date: [Project Start Date]
(b) End Date: [Project End Date]
(c) Key Milestones:
(i) [Project Milestone 1]
(ii) [Project Milestone 2]
(iii)[Project Milestone 3]
Both Parties will review and confirm the schedule to ensure timely completion.
3. TERM.
This Contract shall be effective as of the Effective Date and shall continue for [Contract Term] year(s) unless terminated early or extended by mutual written consent between the Parties or by the provisions of this Contract.
4. SUPPLY OF MATERIALS AND INSPECTION.
In the event that the Company's representative fails to inspect the Materials on the due date, the Contractor shall perform the said test or inspection, and the Materials shall be deemed to be automatically accepted. The Company is entitled to reject the Materials if the performance figures obtained on any such test are outside the specified limits. The Materials shall be manufactured according to the Contractor's standard procedures, including careful inspection, and wherever practical, shall undergo the Contractor's standard tests before dispatch. The Contractor shall invite the Company to witness these tests or any specific test, giving a minimum of [Termination Notice Period] day(s)’ written notice.
5. DELIVERY.
In the event that multiple deliveries are agreed upon in the Contract, the Contractor may deliver the Materials in installments, which shall be invoiced and paid for separately. Any delay in delivery or defect in an installment shall not entitle the Contractor to cancel any other installment.
The Contractor shall ensure that each delivery of the Materials is accompanied by a delivery note that shows all relevant Contractor and Company reference numbers and the type and quantity of the Materials (including the code number of the Materials, wherever applicable).
6. TIME IS OF THE ESSENCE.
This Contract shall commence on the specified day and shall continue until the due date or prior to the set due date. Any delay incurred by the Contractor that is found to be unreasonable shall be considered a breach of this Contract, and the Company shall impose a fine of [Fine for Delivery Failure] for the delay.
7. REPRESENTATION AND WARRANTIES.
(a) The Contractor hereby represents that they have the expertise, knowledge, and experience needed to provide the Materials outlined in this Time and Materials Contract.
(b) The Contractor agrees to uphold all laws and legal requirements of the state of [Governing Law].
(c) In addition, the Contractor shall:
(i) Conform to all material respects with their description and any applicable specification.
(ii) Ensure defect-free Material in terms of design, material, and workmanship.
(iii) Be of satisfactory quality according to Contractor standards.
8. RATES.
The Contractor agrees to the standard pre-determined rates set by the Company. The following rates shall apply unless otherwise mutually modified by both parties.
Time/Materials
Rates
Time
[Hourly Rate] / Hour
[Material 1]
[Material 1 Rate]
[Material 2]
[Material 2 Rate]
9. PAYMENT.
The maximum budget for the Scope of Work is [Maximum Budget in USD]. The Time and Materials described herein shall not exceed the maximum budget under any circumstances. All payments and transactions shall be made in USD through [Mode of Payment]. The payment shall be due upon receipt of the invoice by the Company. Invoices shall be issued upon shipment, and the Company agrees to pay such invoices when due. If invoices are not paid by the due date, the Company will assess a late payment penalty of [Monthly Late Fee Percentage] per month against any unpaid balance from the due date of the invoice until the date of payment. The Contractor reserves the right to disallow any pricing discounts or hold any shipment during any period when outstanding invoices become or remain past due.
10. TAX.
Prices for Materials are exclusive of [Excluded Tax Types]. The Company agrees to pay such taxes and other payments directly or to reimburse the Contractor for all such taxes. Where applicable, such tax or taxes shall be added to the invoice as a separate charge or invoiced separately.
11. SECURITY INTEREST.
The Company shall grant the Contractor a security interest in all of the Company's rights, titles, and interests in the Materials and Products sold hereunder to secure the purchase price payment and the performance of obligations in the event of non-payment or default by the Company.
12. OWNERSHIP RIGHTS.
The Contractor continues to be the sole and exclusive owner of any materials, data, ideas, or inventions shared with the Company during the term of this Contract. The Contractor has no right to use this proprietary information except to provide the services as required by the Company.
13. RELATIONSHIP OF PARTIES.
The Contractor, in the performance of this Contract, shall act in the capacity of an independent contractor and not as a partner, agent, or employee of the Company.
14. LIMITATION OF LIABILITY.
In no event shall either Party be liable to the other Party or any third party for any damages or special, indirect, or consequential damages that might result from any part of this Contract, such as, but not limited to, loss of profit, revenue, or failure in the delivery of services.
15. ASSIGNMENT.
Neither Party may assign this Contract or the rights and obligations thereunder to any third party without the prior express written consent of the other Party, which shall not be unreasonably withheld.
16. CONFIDENTIALITY.
All Confidential Information that is communicated to or obtained by either of the Parties in connection with the above-mentioned services shall be held by them in full faith. At no time shall the Parties use any such Confidential Information obtained through this association, either directly or indirectly, for personal benefit or disclose or communicate such information to any third party. This provision shall remain effective after the termination of this Contract.
17. INDEMNIFICATION.
Each Party indemnifies and holds the other Party and its authorized persons harmless from and against all claims, liabilities, losses, damages, costs, and expenses suffered or incurred by them arising out of or in connection with this Contract unless there is an act of gross negligence, wilful misconduct or bad faith by either Party.
18. ARBITRATION.
In the event of any dispute arising in and out of this Contract between the Parties, it shall be resolved by arbitration. There shall be [Number of Arbitrators] arbitrator(s), who shall be appointed by [Arbitration Appointing Party Name]. The venue of arbitration shall be [Location of Arbitration], and the Seat shall be [State of Seat]. The arbitrator(s)' decision shall be final and binding on both Parties.
19. SEVERABILITY.
In the event that any provision of this Contract is deemed to be invalid or unenforceable, in whole or in part, that part shall be severed from the remainder of this Contract, and all other provisions shall remain in full force and effect as valid and enforceable.
20. GOVERNING LAW.
This Contract shall be governed by and construed in accordance with the laws of the [Governing Law] without regard to conflict of law principles. If the disputes under this Contract are not resolved by Arbitration, the disputes shall be resolved by litigation in the courts of the [Jurisdiction], including the federal courts therein, and all the Parties consent to the jurisdiction of such courts, agree to accept service of process by mail, and hereby waive any jurisdictional or venue defenses otherwise available to it.
21. FORCE MAJEURE.
Neither of the Parties shall be liable for any failure in performance of any obligation under this Contract due to causes beyond that Party's reasonable control (including and not limited to any pandemic, fire, strike, act, or order of public authority and other acts of God) during the pendency of such event.
22. ENTIRE AGREEMENT.
The Parties acknowledge that this Contract sets forth and represents the entire contract between them. If the Parties are willing to change/add/modify any terms, they shall be in writing and signed by both Parties.
23. NOTICES.
Any notices required by this Contract must be in writing and delivered to the appropriate Party by personal delivery, certified mail, prepaid post, or any other similar delivery service.
ACCEPTANCE AND SIGNATURE.
The Parties agree to the terms and conditions set forth above as demonstrated by their signatures as follows:
[Contractor Name]
[Sender Company]
Name:
Name:
Signature:
Signature:
Date:
Date:
Time and Materials Contract Template
Set clear expectations and project scope with your hired contractor through a time-and-materials contract. Outline materials costs, labor rates, and timelines to simplify project management.
Start creating at $59/document or $99/year for unlimited documents
Fill your responses and complete your document
Personalize with a rich editor
eSign document easily and securely
ATTORNEY ADVERTISEMENT: Attorneys advertised on this site are independent attorneys. in your area who’s responsible for this advertisement. LegalZoom.com, Inc. is not an "attorney referral service" or a law firm. The information you provide to LegalZoom is not protected by attorney-client privilege. about this advertisement if you live in Alabama, Missouri, or New York.